Opinion
September 27, 2001.
Order, Supreme Court, New York County (Barry Cozier, J.), entered December 12, 2000, which, to the extent appealed and cross-appealed from, denied defendant contractor's motion for partial summary judgment dismissing plaintiff subcontractor's second, portions of its third, and fourth causes of action in its Amended Complaint, and denied that portion of plaintiff subcontractor's motion to amend to add the City of New York as a defendant and assert against it a cause of action for tortious interference with contractual relations, unanimously affirmed, without costs.
Alan Beckoff, for defendants-respondents.
Joseph P. Dineen, for plaintiff-respondent-appellant.
Sayward Mazur, for defendants-appellants-respondents.
Before: Rosenberger, J.P., Mazzarelli, Ellerin, Saxe, Buckley, JJ.
In these consolidated actions arising from the performance of a public improvement contract, in which the masonry subcontractor seeks to recover from its prime contractor damages for delays allegedly incurred during the course of its performance, the motion court correctly determined that there are triable issues of fact with respect to the cause and nature of the claimed delays. Generally, "absent a contractual commitment to the contrary, a prime contractor is not responsible for delays that its subcontractor may incur unless those delays are caused by some agency or circumstance under the prime contractor's direction or control" (Triangle Sheet Metal Works v. James H. Merritt Co., 79 N.Y.2d 801, 802). While we agree with appellant prime contractor that the claims set forth in the subcontractor's second cause of action seek recovery for delay damages, rather than for extra work, there are triable issues of fact as to whether the delays caused by the City were a substantial contributing cause of the delay for the amount of time claimed and, as a consequence, the corresponding amount of damages sought. It is therefore unnecessary to address the subcontractor's argument that its prime contractor implicitly agreed to pay for the subcontractor's delays, regardless of their cause. We note, however, that such argument is ordinarily unavailing (see, Bovis Lend Lease LMB Inc. v. GCT Venture, Inc., 285 A.D.2d 68).
The subcontractor's motion for leave to add a cause of action for tortious interference against the City was properly denied on the ground that the proposed amendment was insufficient as a matter of law (see,Daniels v. Empire-Orr, Inc., 151 A.D.2d 370). The City, as an intended third-party beneficiary of the subcontract (see, City of New York v. Kalisch-Jarcho, Inc., 161 A.D.2d 252), cannot be held liable for interfering with such agreement (see, e.g., Waterfront N Y Realty Corp. v. Weber, 281 A.D.2d 180; MTI/The Image Group, Inc. v. Fox Studios E., Inc., 262 A.D.2d 20).
THIS CONSTITUTES THE DECISION AND ORDER OF THE SUPREME COURT, APPELLATE DIVISION, FIRST DEPARTMENT.