From Casetext: Smarter Legal Research

United States ex rel. S. H. Anthony, Inc. v. Sauer Inc.

UNITED STATES DISTRICT COURT FOR THE SOUTHERN DISTRICT OF MISSISSIPPI SOUTHERN DIVISION
Jan 17, 2017
CIVIL ACTION NO. 1:15-CV-128-KS-RHW (S.D. Miss. Jan. 17, 2017)

Opinion

CIVIL ACTION NO. 1:15-CV-128-KS-RHW

01-17-2017

UNITED STATES OF AMERICA, FOR THE USE OF S. H. ANTHONY, INC. PLAINTIFF v. SAUER INCORPORATED, et al. DEFENDANTS


ORDER

For the reasons below, the Court denies the Motion in Limine [121] filed by Sauer, Inc. and grants the Motion in Limine [127] filed by S. H. Anthony, Inc. A. Sauer's Motion in Limine [121]

The Court previously discussed the background of this case. See United States ex rel. S. H. Anthony, Inc. v. Sauer, Inc., No. 1:15-CV-128-KS-RHW, 2016 U.S. Dist. LEXIS 169149, at *1-*4 (S.D. Miss. Dec. 7, 2016). Sauer, Inc. ("Sauer") filed a Motion in Limine [121], seeking an order prohibiting S. H. Anthony, Inc. ("SHA") and Hartford Fire Insurance Company ("Hartford") from introducing evidence or argument related to the claims asserted by SHA against Sauer and Federal Insurance Company ("Federal"), which the Court dismissed [112] on October 14, 2016.

The Court found that SHA executed Partial Waiver and Lien Releases which included the following language:

[T]he undersigned does hereby waive, release and relinquish any and all rights, claims, demands, liens, claims for relief, causes of action and the like, whether arising at law, under a contract, in tort, in equity, or otherwise, which the undersigned has now or may have had arising out of the performance of work or the furnishing of labor or materials by the undersigned through [date to be inserted], the effective date of this Waiver and Release pursuant to Subcontract or Purchase Order in
connection with . . . Potable Water System Upgrades Stennis Space Center, MS . . . .

This Waiver and Release applies to all facts, acts, events, circumstances, changes, constructive or actual delays, acceleration, extra work, disruptions, interferences and the like which have occurred, or may be claimed to have occurred, prior to the effective date hereof . . . .
See Exhibit 2 to Motion for Partial Summary Judgment, United States ex rel. S. H. Anthony, Inc. v. Sauer, Inc., No. 1:15-CV-128-KS-RHW (S.D. Miss. Sept. 8, 2016), ECF No. 99-2. Accordingly, the Court dismissed several claims asserted by SHA against Sauer and its surety, Federal. However, the Court specifically reserved ruling on the admissibility of evidence regarding the dismissed claims, or the work which SHA asserts is the basis thereof.

Sauer now argues that, in addition to its claims against Sauer, SHA also waived its right to admit any evidence related to the dismissed claims or the facts underlying them. The language of the waiver does not support this argument. It does not refer to the admission of evidence at a trial on Sauer's own claims against SHA. At most, the document could be possibly interpreted as waiving claims arising from "all facts, acts, events, circumstances, changes, constructive or actual delays, acceleration, extra work, disruptions, interferences and the like which have occurred, or may be claimed to have occurred, prior to the effective date hereof . . . ," and the Court has already dismissed the relevant claims asserted by SHA.

In response to Sauer's motion, SHA provided reasonable explanations as to why evidence of each dismissed claim is relevant to its defense of Sauer's counterclaims. Among other things, Sauer claims that SHA breached its subcontract with Sauer by failing to perform the work in a timely manner. Each of the dismissed claims relate to Field Change Requests ("FCR's") or Change Order Requests ("COR's") which allegedly precipitated delays in the project. SHA intends to introduce evidence as to the factual circumstances surrounding each FCR and COR, and the reasons for delay in performance of the subcontract. SHA's counsel specifically represented in briefing that SHA will not refer to its dismissed claims or the monetary amounts at issue, and that it will not seek recovery of such. The disputed evidence is plainly relevant, and the Court believes that there is little risk that the jury will be confused. Sauer's Motion in Limine [121] is denied. B. SHA's Motion in Limine [127]

The parties agree that the Court should prohibit the admission of any evidence of and references to any past or pending litigation, arbitration, or mediation involving the parties, with the exception of an arbitration involving SHA and its subcontractor, MP NexLevel. The Court grants SHA's Motion in Limine [127] as unopposed.

For these reasons, the Court denies Sauer, Inc.'s Motion in Limine and grants S. H. Anthony, Inc.'s Motion in Limine.

SO ORDERED AND ADJUDGED, on this, the 17th day of January, 2017.

s/ Keith Starrett

UNITED STATES DISTRICT JUDGE


Summaries of

United States ex rel. S. H. Anthony, Inc. v. Sauer Inc.

UNITED STATES DISTRICT COURT FOR THE SOUTHERN DISTRICT OF MISSISSIPPI SOUTHERN DIVISION
Jan 17, 2017
CIVIL ACTION NO. 1:15-CV-128-KS-RHW (S.D. Miss. Jan. 17, 2017)
Case details for

United States ex rel. S. H. Anthony, Inc. v. Sauer Inc.

Case Details

Full title:UNITED STATES OF AMERICA, FOR THE USE OF S. H. ANTHONY, INC. PLAINTIFF v…

Court:UNITED STATES DISTRICT COURT FOR THE SOUTHERN DISTRICT OF MISSISSIPPI SOUTHERN DIVISION

Date published: Jan 17, 2017

Citations

CIVIL ACTION NO. 1:15-CV-128-KS-RHW (S.D. Miss. Jan. 17, 2017)